Mancini Custom Painting Terms and Conditions

Terms and Conditions

These Terms and Conditions ("Terms") govern your use of the  Mancini Custom Painting website  and services. By accessing our website or engaging our services, you agree to comply with and be bound by these Terms. Please read them carefully.

1. Services

Mancini Custom Painting provides a range of painting and related services, including but not limited to interior and exterior painting, power washing, and vinyl siding installation. The specific services to be provided will be detailed in the contract or agreement signed by both parties.

2. Quotes and Estimates

All quotes and estimates provided by Mancini Custom Painting are based on the information available at the time. While we strive for accuracy, final costs may vary due to unforeseen circumstances or changes in project scope. Any significant changes in cost will be communicated promptly.

3. Payment Terms

• Deposits: A deposit may be required before the commencement of work. The amount and terms will be specified in the agreement.
• Payment Schedule: Payment schedules will be detailed in the contract. Payments may be required at various stages of the project.
• Final Payment: The final payment is due upon completion of the project and final inspection.

Failure to adhere to the payment schedule may result in project delays or suspension of services.

4. Cancellation and Rescheduling

• Cancellation: If you need to cancel a scheduled service, please notify us at least 48 hours in advance. Cancellation fees may apply, as specified in your contract.
• Rescheduling: We will do our best to accommodate rescheduling requests. Please provide at least 48 hours’ notice for any changes.

5. Client Responsibilities

Clients are responsible for:

• Access: Providing access to the worksite as required, including ensuring that areas are clear of personal items and obstructions.
• Utilities: Ensuring the availability of necessary utilities, such as water and electricity.
• Permits: Obtaining any necessary permits or permissions required for the work to be performed.

6. Warranties and Guarantees

Mancini Custom Painting stands behind the quality of our work. We offer a limited warranty on our services, as detailed in your contract. This warranty covers defects in workmanship but does not cover:

• Normal Wear and Tear
• Damage Caused by External Factors
• Client-Provided Materials

7. Liability

Mancini Custom Painting is not liable for:

• Injuries or Damages: Any injuries or damages that occur on the client's property, except where caused by our negligence.
• Delays: Delays caused by factors beyond our control, including weather, supply chain issues, or unforeseen site conditions.

8. Privacy

Your privacy is important to us. Please refer to our Privacy Policy for information on how we collect, use, and protect your personal information.

9. Intellectual Property

All content on the Mancini Custom Painting website, including text, graphics, logos, and images, is the property of Mancini Custom Painting and is protected by intellectual property laws. Unauthorized use or reproduction is prohibited.

10. Third-Party Links

Our website may contain links to third-party websites. These links are provided for convenience only, and we do not endorse or assume responsibility for the content or practices of these third-party sites.

11. Dispute Resolution

In the event of a dispute arising from these Terms or our services, both parties agree to attempt to resolve the matter through good-faith negotiations. If a resolution cannot be reached, the dispute may be referred to mediation or arbitration, as agreed upon by both parties.

12. Governing Law

These Terms are governed by and construed in accordance with the laws of the State of Oklahoma. Any legal action or proceeding arising under these Terms shall be brought exclusively in the courts located in Stillwater, Oklahoma.

13. Changes to Terms

Mancini Custom Painting reserves the right to update or modify these Terms at any time. Changes will be effective immediately upon posting on our website, with the updated effective date. Your continued use of our website or services after any changes indicates your acceptance of the new Terms.

14. Contact Information

If you have any questions or concerns about these terms, please contact us at  (405) 780-1329.

By engaging our services or using our website, you acknowledge that you have read, understood, and agreed to be bound by these Terms and Conditions. Thank you for choosing Mancini Custom Painting.

Effective Date: July 14, 2024